Terms and Conditions
1. Acceptance of Terms: By engaging in any business transactions with Colamp Limited, you agree to be bound by the following terms and conditions.
2. Services Offered: Our company specialises in the design, production, and installation of signage and fabrication projects. We provide custom-made signs, banners, displays, and other related products as per the client’s requirements.
3. Order Placement: To initiate an order, clients must provide detailed specifications, including design preferences, dimensions, materials, and any other relevant information. Orders can be placed in person, via email, or through our website.
4. Design Approval: Prior to production, clients will receive a digital proof of the design for review and approval. It is the client’s responsibility to carefully review the proof and communicate any necessary changes or corrections. Once the design is approved, any subsequent modifications may incur additional charges.
5. Pricing and Payment: Our pricing is based on the specific project requirements, including design complexity, materials used, production time, and installation needs. A detailed quote will be provided to the client before commencing any work. Payment terms, including deposit requirements and payment milestones, will be outlined in the quote. Full payment is expected upon completion of the project, unless otherwise agreed upon in writing.
6. Production and Delivery: We strive to complete projects within the agreed-upon timeframe. However, unforeseen circumstances or external factors may affect production and delivery times. We will make reasonable efforts to communicate any delays or changes to the client promptly.
7. Installation and Maintenance: If installation services are included in the project, our team will ensure proper installation according to industry standards. It is the client’s responsibility to provide necessary access and permissions for installation. We are not liable for any damages or issues arising from improper installation or maintenance by the client or third parties.
8. Intellectual Property: All designs, artwork, and intellectual property created by our company remain our exclusive property unless otherwise agreed upon in writing. Clients are prohibited from reproducing, modifying, or using our designs for any other purposes without obtaining written permission.
9. Limitation of Liability: While we strive for accuracy and quality in our work, we are not liable for any indirect, incidental, or consequential damages arising from the use or inability to use our products or services.
10. Governing Law: These terms and conditions shall be governed by and construed in accordance with the laws of United Kingdom. Any disputes arising from these terms and conditions shall be subject to the exclusive jurisdiction of the courts in United Kingdom.
By engaging in business with Colamp Limited, you acknowledge that you have read, understood, and agreed to these terms and conditions.